中国电建江西电建公司墨西哥祖玛公司因吉尼奥风电场风机恢复重建项目项目墨西哥祖玛公司因吉尼奥风电场2×1.5MW风机恢复重建项目箱变基础施工合同采购项目公开谈判采购公告

采购公告

Procurement Announcement

一、 采购条件

本采购项目墨西哥祖玛公司因吉尼奥风电场 2×1.5MW 风机恢复重建项目箱变基础施工合同（以下简称“本项目”）建设资金已落实。项目已具备采购条件，现对该项目进行公开谈判采购。

I. Procurement Conditions

The funding for the substation foundation construction contract for the Inginio Wind Farm 2×1.5MW wind turbine restoration and reconstruction project of Zuma Company in Mexico (hereinafter referred to as "this project") has been secured. The project is now ready for procurement, and open negotiation procurement is hereby invited for this project.

二、 项目概况与采购范围

项目位置： 墨西哥胡奇坦市。

分包工程承包范围：

1.****中心基础主体土建工程（混凝土、钢筋、回填、土方外运、垫层、模板及防水）

2.预埋及附属工程（养护、爬梯、钢板、防火封堵及电缆支架等）

3.检测、测量及临建配套工程

质量要求： 符合墨西哥验收标准。

II. Project Overview and Scope of Procurement

Project Location: Huchitan, Mexico.

Scope of Subcontracted Works:

1. Substation foundation and main civil engineering works (concrete, reinforcement, backfilling, earthwork removal, subbase, formwork, and waterproofing)

2. Embedded and ancillary works (curing, ladders, steel plates, fireproofing, and cable supports, etc.)

3. Testing, surveying, and temporary supporting works

Quality requirements: Meet Mexican acceptance standards.

三、 响应人资格要求

响应人应同时满足以下资格条件：

资质要求： 具有独立法人资格

财务要求： 具有良好的财力状况，近三年无亏损。

信誉要求： 未被列入失信被执行人名单；未被列入中国电建集团黑名单及禁入供应商名单。

税收要求： 响应人必须为增值税一般纳税人，能开具合法合规的增值税专用发票。

III. Respondent Qualification Requirements

Respondents must meet the following qualification requirements simultaneously:

Certificate Requirements:Possess independent legal person status.

Financial Requirements: Have sound financial standing and have no losses in the past three years.

Reputation Requirements:Not listed as a dishonest executor; not listed on the blacklist or prohibited supplier list of China Power Construction Corporation.

Tax Requirements:Respondents must be general VAT taxpayers and able to issue legal and compliant VAT special invoices.

四、 采购文件的获取

***平台： ***网（https://****.cn）在线获取。

IV. Obtaining Procurement Documents

Platform for obtaining documents: Log in to the China Power Construction Sunshine Procurement Website (https://****.cn to obtain the documents online.

五、 响应文件的递交

递交方式： ***网上传的电子响应文件。逾期上传或未按要求的响应文件，采购人不予受理。

V. Submission of Response Documents

Submission Method: Electronic response documents shall be uploaded through the China Power Construction Corporation's Sunshine Procurement Website. Late submissions or response documents that do not meet the requirements will not be accepted by the purchaser.

六、 发布公告的媒介

***网上发布。

VI. Publication Medium

This announcement is published on the China Power Construction Sunshine Procurement website.

七、 联系方式

招标人： 陈年顺

地址： 墨西哥瓦哈卡州

联系人： 陈年顺

电话： 187****4328

邮箱： __****@****.cn

VII. Contact Information

Tenderer: Chen Nianshun

Address: Oaxaca, Mexico

Contact Person: Chen Nianshun

Tel: +86 187****4328

Email: ch****@****.cn